Skip to main content

Ronald Adams Contractor, Inc. v. Lake Borgne Basin Levee District

La. Ct. App.July 11, 2001No. No. 2000-CA-0740Cited 1 time
Defendant WinLake Borgne Basin Levee District
Facing something similar at work?Check your rights — free, private, no sign-up

Case Details

Judge(s)
Byrnes, III, McKay, Waltzer
Status — whether other courts must follow this ruling
Published
Procedural Posture — the stage the case had reached
appeal

Related Laws

No specific laws identified for this ruling.

Claim Types

Breach of Contract

Outcome

The trial court dismissed the contractor's claims for damages, finding that neither the Levee District nor BKI was responsible for the project delays. The appellate court affirmed, holding that the contractor failed to prove its damages with reasonable certainty and that much of the delay resulted from the contractor's own decisions.

What This Ruling Means

I apologize, but I cannot provide a meaningful summary of this employment law case based on the information provided. The case details are extremely limited - there's no excerpt or description of what actually happened in the dispute between Ronald Adams Contractor, Inc. and Lake Borgne Basin Levee District. To write a helpful summary for workers, I would need key information such as: - What the employment dispute was about - What legal issues were raised - How the court ruled - The reasoning behind the decision The filing shows this case was filed in 2001 with an "unknown" outcome and no reported damages, but without knowing the specific facts, legal claims, or court's reasoning, I cannot explain what happened or why it would matter for workers. If you have access to the full court decision or case details, I'd be happy to help summarize those in plain English. A proper summary requires understanding the actual dispute and the court's analysis to provide workers with useful information about their rights and protections.

This summary was generated to explain the ruling in plain English and is not legal advice.

Browse more:Breach of Contract cases

Similar Rulings

James Chappel v. Laboratory Corporation of America, AKA National Health Lab
9th CircuitNov 2000
Mixed Result
Umland v. PLANCO Financial Services, Inc.
3rd CircuitSep 2008
Defendant Win
Harry P. Mendoza v. City of New Orleans and Municipal Police Employees Retirement System
La. Ct. App.Nov 2025
Defendant Win
Johnny Cousain v. Smitty&39;s Supply, Inc. and National Union Fire Insurance Company
La. Ct. App.Sep 2025
Mixed Result
Daniel Russo and Reilly Cavanaugh Versus Onpath Federal Credit Union
La. Ct. App.May 2024
Defendant Win
Read Full OpinionMore Lake Borgne Basin Levee District RulingsAll Rulings

Browse Related

More government & public sector employer cases

Facing something similar at work?

Court rulings like this one are useful, but every situation is different. Take 2 minutes to see which laws may protect you — it's free, private, and no account is required to start.

Check My RightsLearn the Basics

This ruling information is sourced from public court records via CourtListener.com. Case outcomes, claim types, and summaries are extracted using AI analysis and may be incomplete or inaccurate. It is provided for informational and educational purposes only and does not constitute legal advice.

See something wrong, or named in this ruling and want it corrected or redacted? Request a correction.